The federal district court for the Southern District of New York ruled that a failure by plaintiff companies to deliver 3.6 million carbon credits to the defendant company constituted an “Event of Default” under an agreement requiring one of the plaintiffs to deliver credits issued by a carbon credit registry and generated by one of two approved projects in Brazil in exchange for a $29.5 million prepayment. The plaintiff companies invest in carbon credit projects, and the defendant company “sources, invests in, and monitors carbon removal projects around the world and curates a large portfolio of carbon credits that it then resells.” The approved projects involved reducing emissions compared to a baseline of otherwise planned deforestation and forest degradation on large privately owned farmable properties in Brazil. The projects confronted delays, including delays related to overlaps with public park areas, threats by persons understood to be illegal loggers, and lack of access to the land due to social and political unrest related to the 2022 presidential election in Brazil. The court rejected the plaintiffs’ claim that they did not have an obligation to deliver carbon credits because the registry had not issued any carbon credits, which the plaintiffs unsuccessfully argued was a condition precedent to the obligation to deliver credits. The court also was not persuaded by the plaintiffs’ contentions that they were relieved from performance under the doctrines of impossibility and impracticability, due to political turmoil, low river levels that made travel to the sites impracticable, and delays due to changes in the verification process for credits. The court found that the plaintiffs “failed to show that the failure to obtain carbon credits … was unforeseen or could not be guarded against” and that the record reflected that the parties agreed to contract terms placing the risk of delay on the plaintiffs. Because the events that prevented issuance of the credits were foreseeable, the court also rejected the plaintiffs’ argument that the doctrine of frustration of purpose relieved them of their obligations.

Dispute regarding whether plaintiffs defaulted on an agreement requiring delivery of 3.6 million carbon credits generated by projects in Brazil.

Zero Carbon Holdings, LLC v. Aspiration Partners, Inc.

<p>This entry was provided by the Sabin Center for Climate Change Law. Please see the terms of use for citation and licensing of third party data.</p>

New York Federal Court Said Companies’ Failure to Deliver Carbon Credits from Brazil Forest Projects Constituted Default

Filed

United States of America

New York

The Climate Litigation Database

Find climate change litigation data and indicators for {text}.

{text} litigation

Sabin Center for Climate Change Law provides Climate Litigation Database, a comprehensive database of US and Global climate change caselaw

Quickly and easily search through the complete text of thousands of climate change law and policy documents from every country.

Search the Climate Litigation Database

An aim to achieve a quantifiable outcome within a given time-frame, set by an institution such as a national government.

Policy instruments are techniques or tools used by governing authorities to promote certain policies in order to achieve predetermined goals. Put simply, instruments are how a government tries to achieve its goals, with this taxonomy being focused on national policy instruments.

Risk is the potential for adverse consequences resulting from the dynamic interplay between (climate-related) hazards, exposure, and vulnerability of affected human or ecological systems.

Groups  of people who are adversely affected by climate change or the response to it

A set of principles, processes, and practices that build economic and political power to shift from an extractive economy to a regenerative economy.

Justice is the ethical and political framework that addresses fairness, including issues of responsibility, rights, and structural inequity.

Renewable energy means all forms of energy produced from renewable sources in a sustainable manner.

Fossil fuel is a generic term for non-renewable energy sources such as coal, fossil gas, and oil (including crude oil, and petroleum products), that can be used for electricity and heat generation. Fossil fuels are hydrocarbons formed from pressurised and heated organic material buried over millions of years.

Molecules in the atmosphere that play a key role in the greenhouse effect by trapping heat radiating from Earth’s surface.

Area of the economy in which actors engage in identical or related activities.

In human systems, the process of adjustment to actual or expected climate change and its effects, in order to moderate harm, increase resilience or exploit beneficial opportunities. In natural systems, the process of adjustment to actual climate change and its effects; human intervention may facilitate adjustment to expected climate change and its effects.

The management and allocation of funds, assets and investments to meet various objectives

Tradable permits are market-based tools that grant permission for specific activities, frequently used to regulate emissions. These permits can be issued within a trading system to manage environmental impacts.

The processes through which enterprises can identify, prevent, mitigate and account for how they address their actual and potential adverse impacts. Due diligence is the idea that reasonable precautions should be taken to avoid causing harm to people, the environment, or society. It also involves identifying and mitigating risks before they occur.

Either money or something of monetary value is transferred between two or more organisations, people or countries.

Actions or measures to adapt terrestrial systems to climate change.

The release of heat-trapping gases, primarily from human activities such as burning fossil fuels, agriculture and industry.

A long-lived, colourless gas, chiefly emitted from fossil fuel combustion, deforestation and cement production.

Terrestrial means "of the earth" and relates to the risks to ecological system that includes all living organisms and their interactions within land-based environments, such as forests, grasslands, and deserts.

Oil is a combustible liquid fossil fuel composed mainly of hydrocarbons, occurring as crude oil and refined into petroleum products such as petrol, diesel and kerosene.

Jobs that contribute to preserving or restoring the environment. We include jobs which require a high amount of green skills or which spend much of their time on green activities, as well as jobs transforming polluting industries.

Any compulsory, unrequited payment to the government levied on corporations or individuals. This can be for environmental reasons, such as introducing a Carbon tax to set a price that emitters must pay for the greenhouse gases they emit.

Activities that involve planning, designing and building infrastructure, residential, and commercial structures.

This sector involves the wholesale and retail selling of goods.

This sector involves activities to move goods and people, alongside the storage of products.

Activities of government agencies and institutions that provide public services, enforce laws and manage public resources.

This sector includes firms and individuals offering specialised expertise in fields such as law, accounting, consulting, science and engineering.

Activities of businesses and institutions that provide financial services and products to individuals and organisations.

Activities that involve the cultivation of crops and raising of livestock for food, fibre, and other products essential for human life and industry.

Activities that relate to the production of goods and services from forests.

Climate change impacts our society by disrupting the natural, economic and social systems we depend on. Physical hazards and underlying vulnerabilities can lead to increased resource competition for food and water, which can heighten the risk of conflict.

Slow onset events evolve gradually from incremental changes over many years or from increased frequency or intensity of recurring events. As defined in the Cancun Adaptation Framework (2010), slow onset events include risks and impacts from rising temperatures, desertification, biodiversity loss, land and forest degradation, glacial retreat, ocean acidification, sea level rise, and salinization.

New York Federal Court Said Companies’ Failure to Deliver Carbon Credits from Brazil Forest Projects Constituted Default

Policy instrument

Risk

Just transition

Fossil fuel

Greenhouse gas

Economic sector

Adaptation/resilience

Finance